6.1. SR 01-28-2002 - Laserfiche WebLink

Home Browse Search

1.2.2.2 Tile Owner shall periodically update the budget for the Project, including that portion allocated for the Cost of the Work. The Owner shall not significantly increase or decrease the overall budget the portion of the budget allocated for the Cost of the Work, or contingencies included in the overall budget or a portion of the budget, without the agree~ih( ~f the Architect to a corresponding change in the Project scope and quality. 1.2.2.3 The Owner's Designated Representative identified in authorized to act on the Owner's behalf with respect to the Project. The Designated Representative shall render decisions in a timely manner submitted by the Architect in order to avoid unreasonable delay in progress of the Architect's services. 1.2.2.4 The Owner shall furnish the services of consultants Paragraph la.3 or authorize the Architect to furnish them as a services are requested by the Architect and are reasonabb uential designated in vices when Sg.ch 1.2.2.5 Unless otherwise provided in this Agreement, inspections and reports required by law or the mechanical, and chemical tests, tests for air and water materials. 1.2.2.6 The Owner shall furnish all legal, insurance and auditing services, that may be reasonably necessary at any time for the Owner's needs and interests. .2.2.7 The Owner shall provide prompt written notice to the Architect if the Owner becomes ~'his document has important legal consequences. Consultation with an attorney is encouraged with respect to THIS ELECTRONICALLY DRAFTED AIA DOCUMENT MAY BE MADE BY USING AIA DOCUMENT D40L 1.2.3.2 The Architect's services shall be performed as ei~peditio~sl¥ as 'is.iCor~istent with professional skill and care and the orderly progress of the Project, Tlie: 3~rch ~hall submit for the Owner's approval a schedule for the performance of the ArchiteCtS ~ gWliich initially shall be consistent with the time periods established in Subparagraph ii'~!~i]~,~h shall be adjusted, if necessary, as the Project proceeds. This schedule shall include ~S fo, r periods of time required for the ~er's review for the performance 6f"l..,~e :O~gr s consultants, and for approval ; having jurisdiction over'the Project. Time limits established by ~wner shall not, except for re%~nable cause, be exceeded by the 1.2.3.3 The Architects: Designated be authorized to act on the Architect s ]. 2.3.4 The Architect shall maintain the confidentiality of information specifically designated as confidential by ~e OWner, unless withholdihg su:ch information would violate the law, create the risk of' significant harm to the publid or prevent the Architect from establishing a claim or defense in an adjudicatory proce~diiig?:-Th~ Architect shall require of the Architect's consultants similar agreements td /naintain [h~:.'~nfiden:tiality'' ~f information specifically designated as confidential by the Owner. © 1997 AIA® AIA DOCUMENT B141 - 1997 STANDARD FORM AGREEMENT The American Institute of Architects - 1735 New York Avenue N.W. Washington, D.C. 20006-5292 © 1917, 1926, 1948, 1951, 1953, 1958, 1961, 1963, ~966, 1967, 1970, 1974, 1977, 1987, © 1997 by The American Institute of Architects. Reproduction of the material herein or substantial quotation of its provisions without written permission of the AIA violates the copyright laws of the United States and will subject the violator to legal prosecution. WARNING: Unlicensed photocopying violates U.S. copyright laws and will subject the violator to legal prosecution. This document was electronically produced with permission of the AIA and can be reproduced in accordance with your license without violation until the date of expiration as noted below, expiration as noted below, expiration as noted below. User Document: 976141 ch & ps.aia -- t/23/2002 AIA License Number 1017145, which expires on 913012002, 4