|
.1 Costs of labor, including applicable payroll taxes, fringe benefits required by agreement or custom,
<br />workers' compensation insurance, and other employee costs approved by the Architect;
<br />.2 Costs of materials, supplies, and equipment, including cost of transportation, whether incorporated or
<br />consumed;
<br />.3 Rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Contractor
<br />or others;
<br />.4 Costs of premiums for all bonds and insurance, permit fees, and sales, use, or similar taxes, directly
<br />related to the change; and
<br />.5 Costs of supervision and field office personnel directly attributable to the change.
<br />§ 7.3.5 If the Contractor disagrees with the adjustment in the Contract Time, the Contractor may make a Claim in
<br />accordance with applicable provisions of Article 15.
<br />§ 7.3.6 Upon receipt of a Construction Change Directive, the Contractor shall promptly proceed with the change in the
<br />Work involved and advise the Architect of the Contractor's agreement or disagreement with the method, if any,
<br />provided in the Construction Change Directive for determining the proposed adjustment in the Contract Sum or
<br />Contract Time.
<br />§ 7.3.7 A Construction Change Directive signed by the Contractor indicates the Contractor's agreement therewith,
<br />including adjustment in Contract Sum and Contract Time or the method for determining them. Such agreement shall
<br />be effective immediately and shall be recorded as a Change Order.
<br />§ 7.3.8 The amount of credit to be allowed by the Contractor to the Owner for a deletion or change that results in a net
<br />decrease in the Contract Sum shall be actual net cost as confirmed by the Architect. When both additions and credits
<br />covering related Work or substitutions are involved in a change, the allowance for overhead and profit shall be figured
<br />on the basis of net increase, if any, with respect to that change.
<br />§ 7.3.9 Pending final determination of the total cost of a Construction Change Directive to the Owner, the Contractor
<br />may request payment for Work completed under the Construction Change Directive in Applications for Payment. The
<br />Architect will make an interim determination for purposes of monthly certification for payment for those costs and
<br />certify for payment the amount that the Architect determines, in the Architect's professional judgment, to be
<br />reasonably justified. The Architect's interim determination of cost shall adjust the Contract Sum on the same basis as
<br />a Change Order, subject to the right of either party to disagree and assert a Claim in accordance with Article 15.
<br />§ 7.3.10 When the Owner and Contractor agree with a determination made by the Architect concerning the
<br />adjustments in the Contract Sum and Contract Time, or otherwise reach agreement upon the adjustments, such
<br />agreement shall be effective immediately and the Architect will prepare a Change Order. Change Orders may be
<br />issued for all or any part of a Construction Change Directive.
<br />§ 7.4 Minor Changes in the Work
<br />The Architect may order minor changes in the Work that are consistent with the intent of the Contract Documents and
<br />do not involve an adjustment in the Contract Sum or an extension of the Contract Time. The Architect's order for
<br />minor changes shall be in writing. If the Contractor believes that the proposed minor change in the Work will affect the
<br />Contract Sum or Contract Time, the Contractor shall notify the Architect and shall not proceed to implement the
<br />change in the Work. If the Contractor performs the Work set forth in the Architect's order for a minor change without
<br />prior notice to the Architect that such change will affect the Contract Sum or Contract Time, the Contractor waives any
<br />adjustment to the Contract Sum or extension of the Contract Time.
<br />ARTICLE 8 TIME
<br />§ 8.1 Definitions
<br />§ 8.1.1 Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in
<br />the Contract Documents for Substantial Completion of the Work.
<br />§ 8.1.2 The date of commencement of the Work is the date established in the Agreement.
<br />§ 8.1.3 The date of Substantial Completion is the date certified by the Architect in accordance with Section 9.8.
<br />Init. AIA Document A2018— 2017. Copyright© 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1966, 1970, 1976, 1987, 1997, 2007 and 2017 by The
<br />American Institute of Architects. All rights reserved. The "American Institute of Architects," "AIA," the AIA Logo, "A201," and "AIA Contract Documents" are 24
<br />registered trademarks and may not be used without permission. This document was produced by AIA software at 11:53:33 CT on 10/15/2020 under Order
<br />No.6421824392 which expires on 04/24/2021, is not for resale, is licensed for one-time use only, and may only be used in accordance with the AIA Contract
<br />Documents® Terms of Service. To report copyright violations, e-mail copyright@aia.org.
<br />User Notes: (1263491182)
<br />
|